Justia Connecticut Supreme Court Opinion Summaries

Articles Posted in Contracts
by
The Supreme Court affirmed the judgments of the appellate court determining that the four exclusive commercial real estate listing agreements at issue in this case were unenforceable, holding that the appellate court decided that issue correctly.When this case was first brought to the Supreme Court, the Court held that the listing agreements did not violate state antitrust law. On remand for consideration of the remaining grounds on which Defendants had prevailed at trial, the appellate court concluded that the listening agreements incorrectly failed to specify the duration of the brokerage authorization, as required by Conn. Gen. Stat. 20-325a(b) and/or (c), thus rendering them unenforceable. The Supreme Court affirmed, holding (1) the listing agreements complied with the statutory durational requirement; (2) the agreements were personal service contracts requiring the personal performance of the named broker, who died in January 2013; and (3) therefore, Defendants were not liable to Plaintiffs. View "Reserve Realty, LLC v. Windemere Reserve, LLC" on Justia Law

by
The Supreme Court affirmed the judgment of the appellate court affirming the judgment of the trial court denying a property owner's motion for summary judgment in the underlying dispute with a contractor arising from a construction project, holding that the trial court correctly denied Defendants' motion for summary judgment.Defendants hired Plaintiff to serve as a general contractor to renovate a home located on Greenwich property. Defendants later terminated their contractual relationship with Plaintiff. Plaintiff served mechanics' liens on Defendants and brought this action to foreclose its lien. Defendants moved for summary judgment, arguing that the trial court was required to give res judicata effect to the findings of the trial court in a prior action between Plaintiff and one of Defendants' subcontractors. The trial court denied Defendants' summary judgment motion, determine that all four required elements of res judicata were not met. The appellate court affirmed. The Supreme Court affirmed, holding that the appellate court did not err in holding that the presumption of privity that the Supreme Court held to apply in Girolametti v. Michael Horton Associates, Inc., 208 A.3d 1223 (Conn. 2019), did not apply to the instant case. View "Strazza Building & Construction, Inc. v. Harris" on Justia Law

by
The Supreme Court affirmed the decision of the trial court granting summary judgment in favor of Insurer in this action brought to determine whether business losses suffered during the COVID-19 pandemic were covered by the relevant policies, holding that Insured's losses were not covered by the two insurance policies at issue.Before the pandemic, Insurer sold two insurance policies to Insured. Insurer later initiated this action seeking a judgment declaring that Insured's business losses incurred during the COVID-19 pandemic were not covered under the policies. The trial court concluded that there was no coverage under either policy. The Supreme Court affirmed, holding that the trial court properly entered summary judgment for Insurer because Insured's losses plainly and unambiguously were not covered by either policy. View "Hartford Fire Insurance Co. v. Moda, LLC" on Justia Law

by
The Supreme Court affirmed the judgment of the trial court in this dispute over whether a property insurance policy providing coverage for "direct physical loss of or physical damage to" covered property provided coverage for business income losses arising from the suspension of business operations during the COVID-19 pandemic, holding that the trial court correctly granted Defendant's motion for summary judgment.Plaintiffs, who suspended their business operations during the COVID-19 pandemic and consequently lost business income and incurred other expenses, filed claims for losses with Defendants. After Defendants denied the claims Plaintiffs brought this actin seeking a judgment declaring that the relevant insurance policies covered their economic losses under the circumstances. The trial court granted summary judgment for Defendants. The Supreme Court affirmed, holding that because Plaintiffs did not suffer any "direct physical loss" of covered property, there was no genuine issue of material fact as to whether the policies did not cover Plaintiffs' claims. View "Connecticut Dermatology Group, PC v. Twin City Fire Insurance Co." on Justia Law

by
The Supreme Court affirmed the judgment of the trial court denying Defendant's motion to suppress statements he had made during two separately recorded interrogations of him by police officers, holding that the trial court properly denied Defendant's motion to suppress.The two interrogations at issue occurred on the same day. As to the first interrogation, Defendant claimed that the police failed to advise him of his rights pursuant to Miranda v. Arizona, 384 U.S. 436 (1966). Defendant further claimed that the second interrogation was tainted by the alleged illegality of the first interrogation. The trial court denied the motion to suppress and, following a jury trial, convicted Defendant of manslaughter in the first degree with a firearm. The Supreme Court affirmed, holding (1) Miranda warnings were not required for the first interrogation because it was not custodial; and (2) the failure to provide the warnings did not taint the second interrogation. View "State v. Brandon" on Justia Law

by
The Supreme Court reversed the judgment of the trial court finding Plaintiffs responsible for failing to complete a project by the parties' agreed-upon deadline and awarding Defendant $335,000 in liquidated damages on its counterclaim, holding that the trial court's pretrial interpretation of various agreements between the parties was erroneous.At issue was which party was responsible for delays in constructing Dunkin Donuts Park in the City of Hartford. Plaintiffs, the project's developer and the design-builder, sued the City claiming breach of contract, and the City counterclaimed for breach of contract. The trial court concluded, as a matter of law, that Plaintiffs controlled the architect and were therefore liable for changes to and mistakes in the ballpark's design. Thereafter, the jury found Plaintiffs responsible for failing to complete the stadium by the agreed-upon deadline. The Supreme Court reversed, holding that the parties' contracts did not unambiguously grant Plaintiffs legal control of the architect and the stadium's design across all relevant time periods. View "Centerplan Construction Co. v. Hartford" on Justia Law

by
The Supreme Court reversed in part the judgment of the trial court awarding Plaintiff $200,309 in damages for Defendants' breach of a lease agreement, holding that the trial court improperly allocated the burden of proof as to mitigation in determining the damages award.At issue in this appeal was how the executive orders issued by Governor Ned Lamont during the earliest months of the COVID-19 pandemic affected the enforceability of a commercial lease agreement for premises that Defendants leased from Plaintiff. Both parties appealed from the judgment of the trial court awarding Plaintiff damages. The Supreme Court reversed in part, holding that the trial court (1) did not err in determining that the economic effects of the executive orders did not relieve Defendants of their obligations under the lease agreement; but (2) improperly relieved Defendants of their burden of proving that Plaintiff's efforts were commercially unreasonable under the circumstances, thus necessitating a new damages hearing. View "AGW Sono Partners, LLC v. Downtown Soho, LLC" on Justia Law

by
The Supreme Court reversed in part the judgment of the trial court awarding damages in favor of Plaintiff in this action seeking compensatory and punitive damages for breach of a partnership agreement, breach of fiduciary duty, and libel per se, holding that the trial court erred with respect to the libel claim.A jury found in favor of Plaintiff on all three counts and awarded him both compensatory and punitive damages. On appeal, Defendant argued that the trial court erred by denying his motions to set aside the verdict and for judgment notwithstanding the verdict. The Supreme Court reversed in part, holding (1) Plaintiff's claims were not barred by the compulsory counterclaim rule set forth in Fed. R. Civ. P. 13(a)(1); (2) Plaintiff's breach of partnership agreement and breach of fiduciary duty claims did not fail as a matter of law under Karanian v. Maulucci, 440 A.2d 959 (Conn. 1981); and (3) with respect to the libel claim, the trial court erred by admitting the testimony of Plaintiff's expert witness on damages because there was no evidence to support the testimony. View "Chugh v. Kalra" on Justia Law

by
The Supreme Court answered a question certified to the Supreme Court by the United States District Court for the District of Connecticut in this declaratory judgment action by holding that Defendant's plea of nolo contendere could not be used to trigger a criminal acts exclusion in a homeowners insurance policy governed by Connecticut law.At issue was whether Plaintiff, Allstate Insurance Company, could use Defendant's plea of nolo contendere to the charge of assault in the first degree to trigger a criminal acts exclusion that would bar Plaintiff's coverage of Defendant in a civil action involving the same underlying incident. The district court certified the question to the Supreme Court. The Supreme Court answered that Defendant's plea of nolo contendere could not be used by Plaintiff to establish the applicability of the criminal acts exclusion of the relevant policy. View "Allstate Insurance Co. v. Tenn" on Justia Law

by
The Supreme Court affirmed the judgment of the appellate court affirming the judgment in favor of Defendant Theresa Virgulak in this action brought by Plaintiff, Manufacturers and Traders Trust Company, holding that there was no error.The trial court found in favor of Defendant on Plaintiff's foreclosure, reformation, and unjust enrichment claims. The appellate court affirmed. The Supreme Court affirmed, holding (1) the trial court properly declined Plaintiff’s request to reform the mortgage deed to reference that the mortgage deed executed by Defendant was given to secure a note executed by her husband; and (2) the trial court correctly determined that Plaintiff was not entitled to foreclose the mortgage executed by Defendant because Defendant was not a borrower on the note. View "JPMorgan Chase Bank, National Ass'n v. Virgulak" on Justia Law